The Arizona Revised Statutes have been updated to include the revised sections from the 56th Legislature, 1st Regular Session. Please note that the next update of this compilation will not take place until after the conclusion of the 56th Legislature, 2nd Regular Session, which convenes in January 2024.
DISCLAIMER
This online version of the Arizona Revised Statutes is primarily maintained for legislative drafting purposes and reflects the version of law that is effective on January 1st of the year following the most recent legislative session. The official version of the Arizona Revised Statutes is published by Thomson Reuters.
41-2617 - Contracts for procurement of construction; delay; recovery of damages by contractor
41-2617. Contracts for procurement of construction; delay; recovery of damages by contractor
A contract for the procurement of construction shall include a provision which provides for negotiations between the state governmental unit and the contractor for the recovery of damages related to expenses incurred by the contractor for a delay for which the state governmental unit is responsible, which is unreasonable under the circumstances and which was not within the contemplation of the parties to the contract. This section shall not be construed to void any provision in the contract which requires notice of delays, provides for arbitration or other procedure for settlement or provides for liquidated damages.